Proposed Text
18VAC50-22-260. Filing of charges; prohibited acts.
A. All complaints against contractors may be filed with the Department of Professional and Occupational Regulation at any time during business hours, pursuant to § 54.1-1114 of the Code of Virginia.
B. The following are prohibited acts:
1. Failure in any material way to comply with provisions of Chapter 1 (§ 54.1-100 et seq.) or Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia or the regulations of the board.
2. Furnishing substantially inaccurate or incomplete information to the board in obtaining, renewing, reinstating, or maintaining a license.
3. Failure of the responsible management, designated employee, or qualified individual to report to the board, in writing, the suspension or revocation of a contractor license by another state or conviction in a court of competent jurisdiction of a building code violation.
4. Publishing or causing to be published any advertisement relating to contracting which contains an assertion, representation, or statement of fact that is false, deceptive, or misleading.
5. Negligence and/or incompetence in the practice of contracting.
6. Misconduct in the practice of contracting.
7. A finding of improper or dishonest conduct in the practice of contracting by a court of competent jurisdiction or by the board.
8. Failure of all those who engage in residential contracting, excluding subcontractors to the contracting parties and those who engage in routine maintenance or service contracts, to make use of a legible written contract clearly specifying the terms and conditions of the work to be performed. For the purposes of this chapter, residential contracting means construction, removal, repair, or improvements to single-family or multiple-family residential buildings, including accessory-use structures as defined in § 54.1-1100 of the Code of Virginia. Prior to commencement of work or acceptance of payments, the contract shall be signed by both the consumer and the licensee or his agent.
9. Failure of those engaged in residential contracting as defined in this chapter to comply with the terms of a written contract which contains the following minimum requirements:
a. When work is to begin and the estimated completion date;
b. A statement of the total cost of the contract and the amounts and schedule for progress payments including a specific statement on the amount of the down payment;
c. A listing of specified materials and work to be performed, which is specifically requested by the consumer;
d. A "plain-language" exculpatory clause concerning events beyond the control of the contractor and a statement explaining that delays caused by such events do not constitute abandonment and are not included in calculating time frames for payment or performance;
e. A statement of assurance that the contractor will comply with all local requirements for building permits, inspections, and zoning;
f. Disclosure of the cancellation rights of the parties;
g. For contracts resulting from a door-to-door solicitation, a signed acknowledgment by the consumer that he has been provided with and read the Department of Professional and Occupational Regulation statement of protection available to him through the Board for Contractors;
h. Contractor's name, address, license number, class of
license, and classifications or specialty services; and
i. Statement A statement providing that any
modification to the contract, which changes the cost, materials, work to be performed,
or estimated completion date, must be in writing and signed by all parties.;
and
j. A statement notifying consumers of the existence of the Virginia Contractor Transaction Recovery Fund that includes information on how to contact the board for claim information.
10. Failure to make prompt delivery to the consumer before commencement of work of a fully executed copy of the contract as described in subdivisions 8 and 9 of this subsection for construction or contracting work.
11. Failure of the contractor to maintain for a period of five years from the date of contract a complete and legible copy of all documents relating to that contract, including, but not limited to, the contract and any addenda or change orders.
12. Refusing or failing, upon request, to produce to the board, or any of its agents, any document, book, record, or copy of it in the licensee's possession concerning a transaction covered by this chapter or for which the licensee is required to maintain records.
13. Failing to respond to an agent of the board or providing false, misleading or incomplete information to an investigator seeking information in the investigation of a complaint filed with the board against the contractor. Failing or refusing to claim certified mail sent to the licensee's address of record shall constitute a violation of this regulation.
14. Abandonment defined as the unjustified cessation of work under the contract for a period of 30 days or more.
15. The intentional and unjustified failure to complete work contracted for and/or to comply with the terms in the contract.
16. The retention or misapplication of funds paid, for which work is either not performed or performed only in part.
17. Making any misrepresentation or making a false promise that might influence, persuade, or induce.
18. Assisting another to violate any provision of Chapter 1 (§ 54.1-100 et seq.) or Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia, or this chapter; or combining or conspiring with or acting as agent, partner, or associate for another.
19. Allowing a firm's license to be used by another.
20. Acting as or being an ostensible licensee for undisclosed persons who do or will control or direct, directly or indirectly, the operations of the licensee's business.
21. Action by the firm, responsible management as defined in this chapter, designated employee or qualified individual to offer, give, or promise anything of value or benefit to any federal, state, or local employee for the purpose of influencing that employee to circumvent, in the performance of his duties, any federal, state, or local law, regulation, or ordinance governing the construction industry.
22. Where the firm, responsible management as defined in this chapter, designated employee or qualified individual has been convicted or found guilty, after initial licensure, regardless of adjudication, in any jurisdiction, of any felony or of any misdemeanor, there being no appeal pending therefrom or the time of appeal having elapsed. Any plea of guilty or nolo contendere shall be considered a conviction for the purposes of this subdivision. The record of a conviction received from a court shall be accepted as prima facie evidence of a conviction or finding of guilt.
23. Failure to inform the board in writing, within 30 days, that the firm, a member of responsible management as defined in this chapter, its designated employee, or its qualified individual has pleaded guilty or nolo contendere or was convicted and found guilty of any felony or of a Class 1 misdemeanor or any misdemeanor conviction for activities carried out while engaged in the practice of contracting.
24. Having been disciplined by any county, city, town, or any state or federal governing body including action by the Virginia Department of Health, which action shall be reviewed by the board before it takes any disciplinary action of its own.
25. Failure to abate a violation of the Virginia Uniform Statewide Building Code, as amended.
26. Failure of a contractor to comply with the notification requirements of the Virginia Underground Utility Prevention Act, Chapter 10.3 (§ 56-265.14 et seq.) of Title 56 of the Code of Virginia (Miss Utility).
27. Practicing in a classification, specialty service, or class of license for which the contractor is not licensed.
28. Failure to satisfy any judgments.
29. Contracting with an unlicensed or improperly licensed contractor or subcontractor in the delivery of contracting services.
30. Failure to honor the terms and conditions of a warranty.
31. Failure to obtain written change orders, which are signed by both the consumer and the licensee or his agent, to an already existing contract.
32. Failure to ensure that supervision, as defined in this chapter, is provided to all helpers and laborers assisting licensed tradesman.
33. Failure to obtain a building permit or applicable inspection, where required.