Virginia Regulatory Town Hall

Final Text

highlight

Action:
Amendments to Incorporate Changes from Marijuana Legalization
Stage: Final
 
18VAC50-22-40 Requirements for a Class C license

A. A firm applying for a Class C license must meet the requirements of this section.

B. For every classification or specialty in which the firm seeks to be licensed, the firm shall name a qualified individual who meets the following requirements:

1. Is at least 18 years old;

2. Has a minimum of two years of experience in the classification or specialty for which he is the qualifier;

3. Is a full-time employee of the firm as defined in this chapter or is a member of the responsible management of the firm; and

4. a. Has obtained the appropriate certification for the following specialties:

(1) Blast/explosive contracting (Department of Fire Programs explosive use certification);

(2) Fire sprinkler (NICET Sprinkler III certification); and

(3) Radon mitigation (EPA or DEQ accepted radon certification).

b. Has obtained, pursuant to the Individual Licensing and Certification Regulations, a master license for Plumbing, HVAC, Electrical, Gas Fitting, Natural Gas Fitting Provider, and Liquefied Petroleum Gas Contracting.

c. Has completed, for the drug lab remediation specialty, a remediation course approved by the board and a board-approved examination.

d. Has obtained, pursuant to the Individual Licensing and Certification Regulations, certification as an Elevator Mechanic for Elevator Escalator Contracting and certification as a Water Well Systems Provider for Water Well/Pump Contracting.

e. Has been approved by the Board for Contractors for the miscellaneous specialty (MSC).

f. Has completed a board-approved examination for all other classifications and specialties that do not require other certification or licensure.

C. The firm shall provide information for the past five years prior to application on any outstanding, past-due debts and judgments; outstanding tax obligations; defaults on bonds; or pending or past bankruptcies. The firm and all members of the responsible management of the firm shall submit information on any past-due debts and judgments or defaults on bonds directly related to the practice of contracting as defined in Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia.

D. The firm and all members of the responsible management of the firm shall disclose at the time of application any current or previous contractor licenses held in Virginia or in other jurisdictions and any disciplinary actions taken on these licenses. This includes any monetary penalties, fines, suspensions, revocations, surrender of a license in connection with a disciplinary action, or voluntary termination of a license in Virginia or in any other jurisdiction.

E. In accordance with § 54.1-204 of the Code of Virginia, all applicants shall disclose the following information about the firm, all members of the responsible management, and the qualified individual or individuals for the firm:

1. All non-marijuana misdemeanor convictions within three years of the date of application; and

2. All felony convictions during their lifetimes.

Any plea of nolo contendere shall be considered a conviction for purposes of this subsection. The record of a conviction received from a court shall be accepted as prima facie evidence of a conviction or finding of guilt. The board, in its discretion, may deny licensure to any applicant in accordance with § 54.1-204 of the Code of Virginia.

F. A member of responsible management shall have successfully completed a board-approved basic business course.

18VAC50-22-50 Requirements for a Class B license

A. A firm applying for a Class B license must meet the requirements of this section.

B. A firm shall name a designated employee who meets the following requirements:

1. Is at least 18 years old;

2. Is a full-time employee of the firm as defined in this chapter, or is a member of responsible management as defined in this chapter;

3. Has passed a board-approved examination as required by § 54.1-1108 of the Code of Virginia or has been exempted from the exam requirement in accordance with § 54.1-1108.1 of the Code of Virginia; and

4. Has followed all rules established by the board or by the testing service acting on behalf of the board with regard to conduct at the examination. Such rules shall include any written instructions communicated prior to the examination date and any oral or written instructions given at the site on the date of the exam.

C. For every classification or specialty in which the firm seeks to be licensed, the firm shall name a qualified individual who meets the following requirements:

1. Is at least 18 years old;

2. Has a minimum of three years of experience in the classification or specialty for which he is the qualifier;

3. Is a full-time employee of the firm as defined in this chapter or is a member of the responsible management of the firm;

4. a. Has obtained the appropriate certification for the following specialties:

(1) Blast/explosive contracting (Department of Fire Programs explosive use certification);

(2) Fire sprinkler (NICET Sprinkler III certification); and

(3) Radon mitigation (EPA or DEQ accepted radon certification).

b. Has obtained, pursuant to the Individual Licensing and Certification Regulations, a master license for Plumbing, HVAC, Electrical, Gas Fitting, Natural Gas Fitting Provider, and Liquefied Petroleum Gas Contracting.

c. Has completed, for the drug lab remediation specialty, a remediation course approved by the board and a board-approved examination.

d. Has obtained, pursuant to the Individual Licensing and Certification Regulations, certification as an Elevator Mechanic for Elevator Escalator Contracting and certification as a Water Well Systems Provider for Water Well/Pump Contracting.

e. Has been approved by the Board for Contractors for the miscellaneous specialty (MSC).

f. Has completed a board-approved examination for all other classifications and specialties that do not require other certification or licensure.

D. Each firm shall submit information on its financial position. Excluding any property owned as tenants by the entirety, the firm shall state a net worth or equity of $15,000 or more.

E. Each firm shall provide information for the five years prior to application on any outstanding, past-due debts and judgments; outstanding tax obligations; defaults on bonds; or pending or past bankruptcies. The firm, its designated employee, and all members of the responsible management of the firm shall submit information on any past-due debts and judgments or defaults on bonds directly related to the practice of contracting as defined in Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia.

F. The firm, the designated employee, and all members of the responsible management of the firm shall disclose at the time of application any current or previous substantial identities of interest with any contractor licenses issued in Virginia or in other jurisdictions and any disciplinary actions taken on these licenses. This includes any monetary penalties, fines, suspension, revocation, or surrender of a license in connection with a disciplinary action. The board, in its discretion, may deny licensure to any applicant when any of the parties listed in this subsection have had a substantial identity of interest (as deemed in § 54.1-1110 of the Code of Virginia) with any firm that has had a license suspended, revoked, voluntarily terminated or surrendered in connection with a disciplinary action in Virginia or any other jurisdiction.

G. In accordance with § 54.1-204 of the Code of Virginia, all applicants shall disclose the following information about the firm, designated employee, all members of the responsible management, and the qualified individual or individuals for the firm:

1. All non-marijuana misdemeanor convictions within three years of the date of application; and

2. All felony convictions during their lifetimes.

Any plea of nolo contendere shall be considered a conviction for purposes of this subsection. The record of a conviction received from a court shall be accepted as prima facie evidence of a conviction or finding of guilt. The board, in its discretion, may deny licensure to any applicant in accordance with § 54.1-204 of the Code of Virginia.

H. The designated employee or a member of responsible management shall have successfully completed a board-approved basic business course.

18VAC50-22-60 Requirements for a Class A license

A. A firm applying for a Class A license shall meet all of the requirements of this section.

B. A firm shall name a designated employee who meets the following requirements:

1. Is at least 18 years old;

2. Is a full-time employee of the firm as defined in this chapter or is a member of the responsible management of the firm as defined in this chapter;

3. Has passed a board-approved examination as required by § 54.1-1106 of the Code of Virginia or has been exempted from the exam requirement in accordance with § 54.1-1108.1 of the Code of Virginia; and

4. Has followed all rules established by the board or by the testing service acting on behalf of the board with regard to conduct at the examination. Such rules shall include any written instructions communicated prior to the examination date and any oral or written instructions given at the site on the day of the exam.

C. For every classification or specialty in which the firm seeks to be licensed, the firm shall name a qualified individual who meets the following requirements:

1. Is at least 18 years old;

2. Has a minimum of five years of experience in the classification or specialty for which he is the qualifier;

3. Is a full-time employee of the firm as defined in this chapter or is a member of the firm as defined in this chapter or is a member of the responsible management of the firm;

4. a. Has obtained the appropriate certification for the following specialties:

(1) Blast/explosive contracting (DHCD explosive use certification);

(2) Fire sprinkler (NICET Sprinkler III certification); and

(3) Radon mitigation (EPA or DEQ accepted radon certification).

b. Has obtained, pursuant to the Individual Licensing and Certification Regulations, a master license for Plumbing, HVAC, Electrical, Gas Fitting, Natural Gas Fitting Provider, and Liquefied Petroleum Gas Contracting.

c. Has completed, for the drug lab remediation specialty, a remediation course approved by the board and a board-approved examination.

d. Has obtained, pursuant to the Individual Licensing and Certification Regulations, certification as an Elevator Mechanic for Elevator Escalator Contracting and certification as a Water Well Systems Provider for Water Well/Pump Contracting.

e. Has been approved by the Board for Contractors for the miscellaneous specialty (MSC).

f. Has completed a board-approved examination for all other classifications and specialties that do not require other certification or licensure.

D. Each firm shall submit information on its financial position. Excluding any property owned as tenants by the entirety, the firm shall state a net worth or equity of $45,000.

E. The firm shall provide information for the five years prior to application on any outstanding, past-due debts and judgments; outstanding tax obligations; defaults on bonds; or pending or past bankruptcies. The firm, its designated employee, and all members of the responsible management of the firm shall submit information on any past-due debts and judgments or defaults on bonds directly related to the practice of contracting as defined in Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia.

F. The firm, the designated employee, and all members of the responsible management of the firm shall disclose at the time of application any current or previous substantial identities of interest with any contractor licenses issued in Virginia or in other jurisdictions and any disciplinary actions taken on these licenses. This includes any monetary penalties, fines, suspensions, revocations, or surrender of a license in connection with a disciplinary action. The board, in its discretion, may deny licensure to any applicant when any of the parties listed in this subsection have had a substantial identity of interest (as deemed in § 54.1-1110 of the Code of Virginia) with any firm that has had a license suspended, revoked, voluntarily terminated, or surrendered in connection with a disciplinary action in Virginia or in any other jurisdiction.

G. In accordance with § 54.1-204 of the Code of Virginia, all applicants shall disclose the following information about the firm, all members of the responsible management, the designated employee, and the qualified individual or individuals for the firm:

1. All non-marijuana misdemeanor convictions within three years of the date of application; and

2. All felony convictions during their lifetimes.

Any plea of nolo contendere shall be considered a conviction for purposes of this subsection. The record of a conviction received from a court shall be accepted as prima facie evidence of a conviction or finding of guilt. The board, in its discretion, may deny licensure to any applicant in accordance with § 54.1-204 of the Code of Virginia.

H. The designated employee or a member of responsible management shall have successfully completed a board-approved basic business course.

18VAC50-22-62 Requirements for residential building energy analyst firm

A. An applicant for a residential building energy analyst firm license must meet the requirements of this section.

B. The firm shall name a qualified individual who meets all of the following requirements:

1. Is at least 18 years old;

2. Holds a current individual residential building energy analyst license issued by the board; and

3. Is a full-time employee of the firm as defined in this chapter or is a member of the responsible management of the firm.

C. The applicant shall provide documentation, acceptable to the board, that the firm currently carries a minimum of $500,000 of general liability insurance from a company authorized to provide such insurance in the Commonwealth of Virginia.

D. The firm, the qualified individual, and all members of the responsible management of the firm shall disclose at the time of application (i) any current or previous energy analyst or home inspection licenses held in Virginia or in other jurisdictions and (ii) any disciplinary actions taken on these licenses. This includes, but is not limited to, any monetary penalties, fines, suspensions, revocations, surrender of a license in connection with a disciplinary action, or voluntary termination of a license in Virginia or in any other jurisdiction.

E. The firm shall provide information for the past five years prior to application on any outstanding past-due debts, outstanding judgments, outstanding tax obligations, defaults on bonds, or pending or past bankruptcies. The firm, its qualified individual, and all members of the responsible management of the firm shall submit information on any past-due debts and judgments or defaults on bonds directly related to the practice of residential building energy analysis as defined in § 54.1-1144 of the Code of Virginia.

F. In accordance with § 54.1-204 of the Code of Virginia, all applicants shall disclose the following information about the firm, all members of the responsible management, and the qualified individual for the firm:

1. All non-marijuana misdemeanor convictions within three years of the date of application; and

2. All felony convictions during their lifetimes.

Any plea of nolo contendere shall be considered a conviction for purposes of this subsection. The record of a conviction received from a court shall be accepted as prima facie evidence of a conviction or finding of guilt. The board, in its discretion, may deny licensure to any applicant in accordance with § 54.1-204 of the Code of Virginia.

18VAC50-22-260 Filing of charges; prohibited acts

A. All complaints against contractors and residential building energy analyst firms may be filed with the Department of Professional and Occupational Regulation at any time during business hours, pursuant to § 54.1-1114 of the Code of Virginia.

B. The following acts are prohibited acts:

1. Failure in any material way to comply with provisions of Chapter 1 (§ 54.1-100 et seq.) or Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia or the regulations of the board.

2. Furnishing substantially inaccurate or incomplete information to the board in obtaining, renewing, reinstating, or maintaining a license.

3. Failure of the responsible management, designated employee, or qualified individual to report to the board, in writing, the suspension or revocation of a contractor license by another state or conviction in a court of competent jurisdiction of a building code violation.

4. Publishing or causing to be published any advertisement relating to contracting that contains an assertion, representation, or statement of fact that is false, deceptive, or misleading.

5. Negligence or incompetence in the practice of contracting or residential building energy analyses.

6. Misconduct in the practice of contracting or residential building energy analyses.

7. A finding of improper or dishonest conduct in the practice of contracting by a court of competent jurisdiction or by the board.

8. Failure of all those who engage in residential contracting, excluding subcontractors to the contracting parties and those who engage in routine maintenance or service contracts, to make use of a legible written contract clearly specifying the terms and conditions of the work to be performed. For the purposes of this chapter, residential contracting means construction, removal, repair, or improvements to single-family or multiple-family residential buildings, including accessory-use structures as defined in § 54.1-1100 of the Code of Virginia. Prior to commencement of work or acceptance of payments, the contract shall be signed by both the consumer and the licensee or his agent.

9. Failure of those engaged in residential contracting as defined in this chapter to comply with the terms of a written contract that contains the following minimum requirements:

a. When work is to begin and the estimated completion date;

b. A statement of the total cost of the contract and the amounts and schedule for progress payments including a specific statement on the amount of the down payment;

c. A listing of specified materials and work to be performed, which is specifically requested by the consumer;

d. A "plain-language" exculpatory clause concerning events beyond the control of the contractor and a statement explaining that delays caused by such events do not constitute abandonment and are not included in calculating timeframes for payment or performance;

e. A statement of assurance that the contractor will comply with all local requirements for building permits, inspections, and zoning;

f. Disclosure of the cancellation rights of the parties;

g. For contracts resulting from a door-to-door solicitation, a signed acknowledgment by the consumer that he has been provided with and read the Department of Professional and Occupational Regulation statement of protection available to him through the Board for Contractors;

h. Contractor's name, address, license number, class of license, and classifications or specialty services;

i. A statement providing that any modification to the contract, which changes the cost, materials, work to be performed, or estimated completion date, must be in writing and signed by all parties; and

j. Effective with all new contracts entered into after July 1, 2015, a statement notifying consumers of the existence of the Virginia Contractor Transaction Recovery Fund that includes information on how to contact the board for claim information.

10. Failure to make prompt delivery to the consumer before commencement of work of a fully executed copy of the contract as described in subdivisions 8 and 9 of this subsection for construction or contracting work.

11. Failure of the contractor to maintain for a period of five years from the date of contract a complete and legible copy of all documents relating to that contract, including the contract and any addenda or change orders.

12. Refusing or failing, upon request, to produce to the board, or any of its agents, any document, book, record, or copy of it in the licensee's possession concerning a transaction covered by this chapter or for which the licensee is required to maintain records.

13. Failing to respond to an agent of the board or providing false, misleading, or incomplete information to an investigator seeking information in the investigation of a complaint filed with the board against the contractor. Failing or refusing to claim certified mail sent to the licensee's address of record shall constitute a violation of this regulation.

14. Abandonment defined as the unjustified cessation of work under the contract for a period of 30 days or more.

15. The intentional and unjustified failure to complete work contracted for or to comply with the terms in the contract.

16. The retention or misapplication of funds paid, for which work is either not performed or performed only in part.

17. Making any misrepresentation or making a false promise that might influence, persuade, or induce.

18. Assisting another to violate any provision of Chapter 1 (§ 54.1-100 et seq.) or Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia, or this chapter; or combining or conspiring with or acting as agent, partner, or associate for another.

19. Allowing a firm's license to be used by another.

20. Acting as or being an ostensible licensee for undisclosed persons who do or will control or direct, directly or indirectly, the operations of the licensee's business.

21. Action by the firm, responsible management as defined in this chapter, designated employee, or qualified individual to offer, give, or promise anything of value or benefit to any federal, state, or local employee for the purpose of influencing that employee to circumvent, in the performance of his duties, any federal, state, or local law, regulation, or ordinance governing the construction industry.

22. Where the firm, responsible management as defined in this chapter, designated employee, or qualified individual has been convicted or found guilty, after initial licensure, regardless of adjudication, in any jurisdiction, of any felony or of any non-marijuana misdemeanor, there being no appeal pending therefrom or the time of appeal having elapsed. Any plea of guilty or nolo contendere shall be considered a conviction for the purposes of this subdivision. The record of a conviction received from a court shall be accepted as prima facie evidence of a conviction or finding of guilt.

23. Failure to inform the board in writing, within 30 days, that the firm, a member of responsible management as defined in this chapter, its designated employee, or its qualified individual has pleaded guilty or nolo contendere or was convicted and found guilty of any felony or of a Class 1 misdemeanor or any non-marijuana misdemeanor conviction for activities carried out while engaged in the practice of contracting.

24. Having been disciplined by any county, city, town, or any state or federal governing body including action by the Virginia Department of Health, which action shall be reviewed by the board before it takes any disciplinary action of its own.

25. Failure to abate a violation of the Virginia Uniform Statewide Building Code, as amended (13VAC5-63).

26. Failure of a contractor to comply with the notification requirements of the Virginia Underground Utility Damage Prevention Act, Chapter 10.3 (§ 56-265.14 et seq.) of Title 56 of the Code of Virginia (Miss Utility).

27. Practicing in a classification, specialty service, or class of license for which the contractor is not licensed.

28. Failure to satisfy any judgments.

29. Contracting with an unlicensed or improperly licensed contractor or subcontractor in the delivery of contracting services.

30. Failure to honor the terms and conditions of a warranty.

31. Failure to obtain written change orders, which are signed by both the consumer and the licensee or his agent, to an already existing contract.

32. Failure to ensure that supervision, as defined in this chapter, is provided to all helpers and laborers assisting licensed tradesman.

33. Failure to obtain a building permit or applicable inspection, where required.

34. Failure of a residential building energy analyst firm to ensure that residential building energy analyses conducted by the firm are consistent with the requirements set forth by the board, the U.S. Environmental Protection Agency, the U.S. Department of Energy, or the Energy Star Program.

35. Failure of a residential building energy analyst firm to maintain the general liability insurance required in 18VAC50-22-62 C at any time while licensed by the board.

36. Failure of a contractor holding the drug lab remediation specialty to ensure that remediation work conducted by the firm or properly licensed subcontractors is consistent with the guidelines set forth by the U.S. Environmental Protection Agency, Virginia Department of Environmental Quality, Virginia Department of Health, or Virginia Department of Forensic Science.

37. Failure of a contractor to appropriately classify all workers as employees or as independent contractors as provided by law.

18VAC50-30-30 General qualifications for licensure or certification

Every applicant to the Board for Contractors for licensure or certification shall meet the requirements and have the qualifications provided in this section.

1. The applicant shall be at least 18 years old.

2. Unless otherwise exempted, the applicant shall meet the current educational requirements by passing all required courses prior to the time the applicant sits for the examination and applies for licensure or certification.

3. Unless exempted, the applicant shall have passed the applicable examination provided by the board or by a testing organization acting on behalf of the board.

4. The applicant shall meet the experience requirements as set forth in 18VAC50-30-40.

5. In those instances where the applicant is required to take the license or certification examination, the applicant shall follow all rules established by the board with regard to conduct at the examination. Such rules shall include any written instructions communicated prior to the examination date and any instructions communicated at the site, either written or oral, on the date of the examination. Failure to comply with all rules established by the board and the testing organization with regard to conduct at the examination shall be grounds for denial of application.

6. The applicant shall disclose his the applicant's physical home address; a post office box alone is not acceptable.

7. Each nonresident applicant for a license or certification card shall file and maintain with the department an irrevocable consent for the department to serve as service agent for all actions filed in any court in this Commonwealth. In those instances where service is required, the director of the department will mail the court document to the individual at the address of record.

8. The applicant shall sign, as part of the application, a statement certifying that the applicant has read and understands Article 3 (§ 54.1-1128 et seq.) of Chapter 11 of Title 54.1 of the Code of Virginia and this chapter.

9. The board may make further inquiries and investigations with respect to the qualifications of the applicant or require a personal interview with the applicant.

10. In accordance with § 54.1-204 of the Code of Virginia, each applicant shall disclose a conviction, in any jurisdiction, of any misdemeanor or felony or non-marijuana misdemeanor. Any plea of nolo contendere shall be considered a conviction for the purpose of this subdivision. The record of conviction received from a court shall be accepted as prima facie evidence of a conviction or finding of guilt. The board, at its discretion, may deny licensure or certification to any applicant in accordance with § 54.1-204 of the Code of Virginia.

11. The applicant shall report any suspensions, revocations, or surrendering of a certificate or license in connection with a disciplinary action or which has been the subject of discipline in any jurisdiction prior to applying for licensure or certification in Virginia. The board, at its discretion, may deny licensure or certification to any applicant based on prior suspensions, revocations, or surrender of certifications or licenses based on disciplinary action by any jurisdiction.

18VAC50-30-190 Prohibited acts

Any of the following are cause for disciplinary action:

1. Failure in any material way to comply with provisions of Chapter 1 (§ 54.1-100 et seq.) or Chapter 11 (§ 54.1-1100 et seq.) of Title 54.1 of the Code of Virginia or the regulations of the board;

2. Furnishing substantially inaccurate or incomplete information to the board in obtaining, renewing, reinstating, or maintaining a license or certification card;

3. Where the regulant has failed to report to the board, in writing, the suspension or revocation of a tradesman, liquefied petroleum gas fitter or natural gas fitter provider license, certificate or card, or backflow prevention device worker, water well systems provider, elevator mechanic, or accessibility mechanic certification card, by another state or a conviction in a court of competent jurisdiction of a building code violation;

4. Negligence or incompetence in the practice of a tradesman, liquefied petroleum gas fitter, natural gas fitter provider, backflow prevention device worker, elevator mechanic, accessibility mechanic, water well systems provider, or automatic fire sprinkler inspector;

5. Misconduct in the practice of a tradesman, liquefied petroleum gas fitter, natural gas fitter provider, backflow prevention device worker, elevator mechanic, accessibility mechanic, water well systems provider, or automatic fire sprinkler inspector;

6. A finding of improper or dishonest conduct in the practice of a tradesman, liquefied petroleum gas fitter, natural gas fitter provider, backflow prevention device worker, elevator mechanic, accessibility mechanic, or water well systems provider by a court of competent jurisdiction;

7. For licensed tradesmen, liquefied petroleum gas fitters or natural gas fitter providers performing jobs under $1,000, or backflow prevention device workers, elevator mechanics, accessibility mechanics, or water well systems providers performing jobs of any amount, abandonment, the intentional and unjustified failure to complete work contracted for, or the retention or misapplication of funds paid, for which work is either not performed or performed only in part (unjustified cessation of work under the contract for a period of 30 days or more shall be considered evidence of abandonment);

8. Making any misrepresentation or making a false promise of a character likely to influence, persuade, or induce;

9. Aiding or abetting an unlicensed contractor to violate any provision of Chapter 1 or Chapter 11 of Title 54.1 of the Code of Virginia or these regulations or combining or conspiring with or acting as agent, partner, or associate for an unlicensed contractor; or allowing one's license or certification to be used by an unlicensed or uncertified individual;

10. Where the regulant has offered, given, or promised anything of value or benefit to any federal, state, or local government employee for the purpose of influencing that employee to circumvent, in the performance of his duties, any federal, state, or local law, regulation, or ordinance governing the construction industry;

11. Where the regulant has been convicted or found guilty, after initial licensure or certification, regardless of adjudication, in any jurisdiction of any felony or of a misdemeanor involving lying, cheating or stealing, sexual offense, non-marijuana drug distribution, physical injury, or relating to the practice of the profession, there being no appeal pending therefrom or the time of appeal having elapsed. Any pleas of guilty or nolo contendere shall be considered a conviction for the purposes of this subdivision. The record of a conviction certified or authenticated in such form as to be admissible in evidence under the laws of the jurisdiction where convicted shall be admissible as prima facie evidence of such guilt;

12. Having failed to inform the board in writing, within 30 days, that the regulant has pleaded guilty or nolo contendere or was convicted and found guilty of any felony or a misdemeanor involving lying, cheating, stealing, sexual offense, non-marijuana drug distribution, physical injury, or relating to the practice of the profession;

13. Having been disciplined by any county, city, town, or any state or federal governing body for actions relating to the practice of any trade, backflow prevention device work, elevator or accessibility work, or water well systems provider work, which action shall be reviewed by the board before it takes any disciplinary action of its own;

14. Failure to comply with the Virginia Uniform Statewide Building Code (13VAC5-63);

15. Practicing in a classification or specialty service for which the regulant is not licensed or certified;

16. Failure to obtain any document required by the Virginia Department of Health for the drilling, installation, maintenance, repair, construction, or removal of water wells, water well systems, water well pumps, or other water well equipment;

17. Failure to obtain a building permit or applicable inspection where required;

18. Failure to perform a residential building energy analysis consistent with the requirements set forth by the board, the U.S. Environmental Protection Agency, the U.S. Department of Energy, or the Energy Star Program;

19. Failure of a residential building energy analyst to maintain the general liability insurance required in 18VAC50-30-40 I 4; and

20. Failure of a certified automatic fire sprinkler inspector to continually maintain the certification required in § 54.1-1147 of the Code of Virginia.